SKYWORLD HOLDINGS SDN BHD v Neurogine Sdn Bhd

b-02nccw-1312-08-2023 Court of Appeal (Mahkamah Rayuan) 21 August 2025 • B-02(NCC)(W)-1312-08/2023 • 3 min read

Catchwords

Design and development of the app Design & Development Of Sky Chat, Wallet & Payment Gateway with Cloud Base Project-Neurogine's access as the mobile application developer to Google Play Store- additional change requests made by the iNetSOHO team- signing off by iNetSOHO after the User Acceptance Test and the Functional Test- Skyworld's claim that the app was not functioning was based on the mere oral assertion of its witnesses- parties had adopted a flexible approach with regard to the timeline for completion- denied user access to Google Play Store by iNetSOHO- failure to complete the Project particularly the e-wallet and Red Packet module was not due to any breach on Neurogine’s part but was consequent upon iNetSOHO's actions in denying access to Google Play Store due to payment issues- change made by Skyworld for additional services- payment of RM 490,000.00 was towards the second quotation.- Skyworld had knowledge of the second quotation.

Practice Areas

Judges (3)

Choo Kah Sing Coram Collin Lawrence Sequerah Delivered Ravinthran a/l Paramaguru Coram

Parties (2)

Neurogine Sdn Bhd Respondent SKYWORLD HOLDINGS Sdn Bhd Appellant

Judgment

Read the full judgment on the official Malaysia Courts portal.

Read on eJudgment

Source: eJudgment (b-02nccw-1312-08-2023)