Neurogine Sdn Bhd

Organisation 1 case

About Neurogine Sdn Bhd

Neurogine Sdn Bhd appears as a party in 1 judgment in the MY Case Law database, spanning August 2025 to August 2025. Neurogine Sdn Bhd appeared as respondent in 1 case. Cases span the Court of Appeal (1).

How many court cases involve Neurogine Sdn Bhd?

Neurogine Sdn Bhd appears in 1 published judgment from August 2025 to August 2025. Most commonly as respondent (1 cases).

Practice Areas

Design and development of the app Design & Development Of Sky Chat, Wallet & Payment Gateway with Cloud Base Project-Neurogine's access as the mobile application developer to Google Play Store- additional change requests made by the iNetSOHO team- signing off by iNetSOHO after the User Acceptance Test and the Functional Test- Skyworld's claim that the app was not functioning was based on the mere oral assertion of its witnesses- parties had adopted a flexible approach with regard to the timeline for completion- denied user access to Google Play Store by iNetSOHO- failure to complete the Project particularly the e-wallet and Red Packet module was not due to any breach on Neurogine’s part but was consequent upon iNetSOHO's actions in denying access to Google Play Store due to payment issues- change made by Skyworld for additional services- payment of RM 490,000.00 was towards the second quotation.- Skyworld had knowledge of the second quotation. 1

Respondent (1)

b-02nccw-1312-08-2023 MYCOA

SKYWORLD HOLDINGS SDN BHD v Neurogine Sdn Bhd

21 August 2025