SKYWORLD HOLDINGS Sdn Bhd

Organisation 2 cases

About SKYWORLD HOLDINGS Sdn Bhd

SKYWORLD HOLDINGS Sdn Bhd appears as a party in 2 judgments in the MY Case Law database, spanning April 2021 to August 2025. SKYWORLD HOLDINGS Sdn Bhd appeared as appellant in 2 cases. Cases span the Court of Appeal (1), Federal Court (1).

How many court cases involve SKYWORLD HOLDINGS Sdn Bhd?

SKYWORLD HOLDINGS Sdn Bhd appears in 2 published judgments from April 2021 to August 2025. Most commonly as appellant (2 cases).

Practice Areas

Trade Mark 1 Passing off 1 Design and development of the app Design & Development Of Sky Chat, Wallet & Payment Gateway with Cloud Base Project-Neurogine's access as the mobile application developer to Google Play Store- additional change requests made by the iNetSOHO team- signing off by iNetSOHO after the User Acceptance Test and the Functional Test- Skyworld's claim that the app was not functioning was based on the mere oral assertion of its witnesses- parties had adopted a flexible approach with regard to the timeline for completion- denied user access to Google Play Store by iNetSOHO- failure to complete the Project particularly the e-wallet and Red Packet module was not due to any breach on Neurogine’s part but was consequent upon iNetSOHO's actions in denying access to Google Play Store due to payment issues- change made by Skyworld for additional services- payment of RM 490,000.00 was towards the second quotation.- Skyworld had knowledge of the second quotation. 1

Appellant (2)

b-02nccw-1312-08-2023 MYCOA

SKYWORLD HOLDINGS SDN BHD v Neurogine Sdn Bhd

21 August 2025

02f-50-09-2020w MYFC

1. ) SKYWORLD HOLDINGS SDN. BHD. 2. ) SKYWORLD GLOBAL SDN. BHD. 3. ) SKYWORLD (SABAH) SDN. BHD. 4. ) SKY WORLD CITY BERHAD 5. ) YONG FOOK MING 6. ) LEE CHIA LIN v 1. ) SKYWORLD DEVELOPMENT SDN. BHD. 2. ) SKYWORLD CAPITAL BERHAD

6 April 2021