Sagamuda Civil Sdn Bhd

Organisation 1 case

About Sagamuda Civil Sdn Bhd

Sagamuda Civil Sdn Bhd appears as a party in 1 judgment in the MY Case Law database, spanning July 2025 to July 2025. Sagamuda Civil Sdn Bhd appeared as respondent in 1 case. Cases span the Court of Appeal (1).

How many court cases involve Sagamuda Civil Sdn Bhd?

Sagamuda Civil Sdn Bhd appears in 1 published judgment from July 2025 to July 2025. Most commonly as respondent (1 cases).

Practice Areas

PAM Contract 2006- delay-Liquidated ascertained damages (LAD)-Non-compliance with schedule-Whether contractor in breach-Whether termination of contract unlawful-Counterclaim for unpaid works-Final Account-Contractor’s entitlement-Commencement and completion dates-Condition precedent-Piling and utilities works-Delay in progress- Evidence-Res ipsa loquitur-Delay attributable to contractor 1

Respondent (1)

p-01cw-247-04-2024 MYCOA

MAJLIS BANDARAYA PULAU PINANG v Sagamuda Civil Sdn Bhd

6 July 2025