DELICATE BUILDERS SDN. BHD. v INTIGA SDN. BHD.

wa-12bc-11-09-2023 High Court (Mahkamah Tinggi) 21 April 2025 • WA-12BC-11-09/2023

Catchwords

Whether the delay to the completion of the Project is caused by the defendant - Whether the plaintiff is entitled to back charge the sum of RM131,440.00 on the defendant for the appointment of NYC - Whether the plaintiff is entitled to back charge the sum of RM204,526.98 for scaffolding - Whether the plaintiff is entitled to back charge the sum of RM96,968.80 to the defendant for overtime for Stone Installer - Whether the Defendant is entitled to the sum of RM360,691.17 being the balance amount for work done for the Project

Practice Areas

Whether the delay to the completion of the Project is caused by the defendant

Judges (1)

Aliza binti Sulaiman Delivered

Parties (2)

DELICATE BUILDERS Sdn Bhd Appellant INTIGA Sdn Bhd Respondent

Case Significance

DELICATE BUILDERS SDN. BHD. v INTIGA SDN. BHD. is a High Court (Mahkamah Tinggi) decision dated April 21, 2025 (citation: wa-12bc-11-09-2023). The case was decided by Aliza binti Sulaiman.

What was the outcome of DELICATE BUILDERS SDN. BHD. v INTIGA SDN. BHD.?

DELICATE BUILDERS SDN. BHD. v INTIGA SDN. BHD. is a High Court decision dated April 21, 2025. The case was heard by Aliza binti Sulaiman. See the full judgment for details.